Terms & Conditions
Last Updated: 13 August 2026
Welcome to Adelaide Kitchen Refresh. These Terms & Conditions apply to your use of our website and your interactions with our business.
By accessing this website, submitting an enquiry, requesting a quote, or using our services, you agree to these Terms & Conditions where applicable.
By accessing this website, submitting an enquiry, requesting a quote, or using our services, you agree to these Terms & Conditions where applicable.
About Us
Adelaide Kitchen Refresh provides kitchen renovation and improvement services, including cabinet refacing, benchtop upgrades, cabinet modifications, custom kitchen building, and related services.
Information provided on this website is intended as general information about our business and services.
Information provided on this website is intended as general information about our business and services.
Our Services
The scope of each project will be discussed with you and confirmed through a quotation, proposal, or separate project agreement where applicable.
Services, materials, finishes, pricing, and availability may vary depending on your property, project requirements, supplier availability, and other relevant factors.
Where a separate quotation or project agreement contains terms specific to your renovation, those project-specific terms will apply to that work.
Services, materials, finishes, pricing, and availability may vary depending on your property, project requirements, supplier availability, and other relevant factors.
Where a separate quotation or project agreement contains terms specific to your renovation, those project-specific terms will apply to that work.
Quotes & Pricing
Any pricing displayed on our website is general information only unless clearly stated otherwise.
Project pricing will normally be provided after we have assessed your requirements. Quotes may take into account the scope of work, materials, labour, measurements, site conditions, and other project requirements.
A quotation will remain valid for the period stated in the quotation. Prices may change if the scope of work changes or if additional work is requested.
Project pricing will normally be provided after we have assessed your requirements. Quotes may take into account the scope of work, materials, labour, measurements, site conditions, and other project requirements.
A quotation will remain valid for the period stated in the quotation. Prices may change if the scope of work changes or if additional work is requested.
Deposits & Payments
Payment requirements, including any deposit and progress payments, will be outlined in your quotation or project agreement.
Payments must be made according to the agreed payment schedule and are subject to applicable Australian and South Australian laws.
Failure to make an agreed payment may result in work being delayed or suspended where permitted by law and the applicable agreement.
Payments must be made according to the agreed payment schedule and are subject to applicable Australian and South Australian laws.
Failure to make an agreed payment may result in work being delayed or suspended where permitted by law and the applicable agreement.
Changes to Your Project
If you request changes after accepting a quotation or after work has commenced, those changes may affect the project price, materials, and completion timeframe.
Where appropriate, additional or varied work will be discussed with you and confirmed before proceeding.
We encourage all significant project changes to be confirmed in writing so that both parties clearly understand the revised scope of work.
Where appropriate, additional or varied work will be discussed with you and confirmed before proceeding.
We encourage all significant project changes to be confirmed in writing so that both parties clearly understand the revised scope of work.
Project Timeframes
We aim to complete all projects within the estimated timeframe provided to you.
However, completion dates may occasionally be affected by circumstances outside our reasonable control, including supplier delays, material availability, unexpected site conditions, weather, access issues, or delays involving other contractors.
We will make reasonable efforts to keep you informed if circumstances significantly affect your project schedule.
However, completion dates may occasionally be affected by circumstances outside our reasonable control, including supplier delays, material availability, unexpected site conditions, weather, access issues, or delays involving other contractors.
We will make reasonable efforts to keep you informed if circumstances significantly affect your project schedule.
Customer Responsibilities
To help us complete your project efficiently and safely, you are responsible for providing accurate project information and reasonable access to the property when required.
You should also advise us of any known conditions that may affect the work, including existing damage, access restrictions, structural concerns, plumbing or electrical issues, or other relevant property conditions.
Additionalwork required because of previously unknown site conditions may be quoted separately where appropriate.
You should also advise us of any known conditions that may affect the work, including existing damage, access restrictions, structural concerns, plumbing or electrical issues, or other relevant property conditions.
Additionalwork required because of previously unknown site conditions may be quoted separately where appropriate.
Materials, Colours & Finishes
We aim to provide materials, colours, finishes, and products consistent with the selections agreed for your project.
However, natural materials, manufactured finishes, colours, grains, patterns, and product samples may have minor variations.
Product availability may also change. If an agreed product or material becomes unavailable, we will discuss suitable alternatives with you before making a significant substitution.
However, natural materials, manufactured finishes, colours, grains, patterns, and product samples may have minor variations.
Product availability may also change. If an agreed product or material becomes unavailable, we will discuss suitable alternatives with you before making a significant substitution.
Cancellations & Rescheduling
If you need to cancel or reschedule a consultation or project, please contact us as soon as possible.
Any cancellation charges, refund arrangements, or treatment of deposits will depend on the stage of the project, work already completed, materials already ordered, your applicable quotation or contract, and your rights under Australian law.
Nothing in these Terms & Conditions is intended to exclude any cancellation, refund, or other rights that cannot legally be excluded.
Any cancellation charges, refund arrangements, or treatment of deposits will depend on the stage of the project, work already completed, materials already ordered, your applicable quotation or contract, and your rights under Australian law.
Nothing in these Terms & Conditions is intended to exclude any cancellation, refund, or other rights that cannot legally be excluded.
Consumer Guarantees
Our goods and services come with rights and guarantees that may apply under the Australian Consumer Law.
Nothing in these Terms & Conditions excludes, restricts, or modifies any consumer guarantee, right, or remedy that cannot legally be excluded or restricted.
If there is an issue with our work or the products or services we have supplied, please contact us so we can review the matter and work toward an appropriate resolution.
Nothing in these Terms & Conditions excludes, restricts, or modifies any consumer guarantee, right, or remedy that cannot legally be excluded or restricted.
If there is an issue with our work or the products or services we have supplied, please contact us so we can review the matter and work toward an appropriate resolution.
Website Information
We make reasonable efforts to ensure the information on our website is accurate and current.
However, website content may occasionally contain errors, become outdated, or change without notice. Images displayed on the website may also be illustrative and may not exactly represent every material, finish, product, or completed project.
For information specific to your renovation, please rely on the details confirmed in your quotation or project agreement.
However, website content may occasionally contain errors, become outdated, or change without notice. Images displayed on the website may also be illustrative and may not exactly represent every material, finish, product, or completed project.
For information specific to your renovation, please rely on the details confirmed in your quotation or project agreement.
Intellectual Property
Unless otherwise stated, the content on this website—including text, branding, graphics, photographs, designs, and other materials—is owned by or licensed to Adelaide Kitchen Refresh.
Website content must not be copied, reproduced, republished, distributed, or used commercially without permission, except where permitted by law.
Third-Party Links
Our website may contain links to third-party websites or platforms for your convenience.
We do not control these external websites and are not responsible for their content, availability, security, or practices.
Your use of third-party websites is subject to their own terms and policies.
We do not control these external websites and are not responsible for their content, availability, security, or practices.
Your use of third-party websites is subject to their own terms and policies.
Limitation of Liability
To the maximum extent permitted by law, Adelaide Kitchen Refresh will not be responsible for indirect or consequential loss arising solely from your use of this website.
Nothing in this section or elsewhere in these Terms & Conditions is intended to exclude or limit liability where doing so would be prohibited by law, including any rights available under the Australian Consumer Law.
Nothing in this section or elsewhere in these Terms & Conditions is intended to exclude or limit liability where doing so would be prohibited by law, including any rights available under the Australian Consumer Law.
Privacy
Your privacy is important to us.
Any personal information collected through our website or services will be managed in accordance with our Privacy Policy and applicable privacy requirements.
Please review our Privacy Policy for more information about how we collect, use, store, and protect personal information.
Any personal information collected through our website or services will be managed in accordance with our Privacy Policy and applicable privacy requirements.
Please review our Privacy Policy for more information about how we collect, use, store, and protect personal information.
Resolving Concerns
If you have a concern about our services or a project, please contact us first so we have an opportunity to review the issue and work toward a reasonable resolution.
Where a matter cannot be resolved directly, either party may pursue other dispute resolution options or remedies available under applicable Australian or South Australian law.
Where a matter cannot be resolved directly, either party may pursue other dispute resolution options or remedies available under applicable Australian or South Australian law.
Governing Law
These Terms & Conditions are governed by the laws applicable in South Australia, Australia, together with applicable Commonwealth laws.
Any dispute relating to these Terms & Conditions will be subject to the jurisdiction of the courts and tribunals that have authority in South Australia, subject to any rights available under applicable law.
Any dispute relating to these Terms & Conditions will be subject to the jurisdiction of the courts and tribunals that have authority in South Australia, subject to any rights available under applicable law.
Changes to These Terms
We may update these Terms & Conditions from time to time to reflect changes to our website, services, business practices, or legal requirements.
The latest version will be published on this website with the updated date displayed at the top of the page.
The latest version will be published on this website with the updated date displayed at the top of the page.
Contact Us
If you have questions about these Terms & Conditions, our services, or an upcoming project, please contact us.
Adelaide Kitchen Refresh
Email: mark@adelaidekitchenrefresh.com
Phone: 0418 883 095
Email: mark@adelaidekitchenrefresh.com
Phone: 0418 883 095